Chat on WhatsApp call

Terms and Conditions

Terms and Conditions

  • Company Name: Classic SK Home
  • Email: admin@classicskhome.com
  • Phone: 9092771616
  • Phone: 9750345444
  • Address: CLASSIC SK HOME PVT.LTD., #C11, 2nd Cross, Anna Nagar, Nitish Apartments, SF1, Chengalpattu - 603 001.

1. Agreement Overview

This Terms and Conditions document represents a legally binding agreement between the customer (“Client”) and Classic SK Home, concerning the planning, construction, and delivery of residential or commercial buildings.

2. Scope of Work

Classic SK Home agrees to provide home construction services as per the mutually accepted plan, estimate, and specifications. Any modifications or additional work will require written approval and may affect the cost and timeline.

3. Quotation and Payments

  • The quotation is based on current material and labor costs.
  • Payment must be made in agreed-upon installments at key project milestones.
  • Delay in payment may lead to project suspension and penalties.
  • All payments are non-refundable once work has commenced.

4. Timeline

  • Estimated completion dates will be provided.
  • Delays due to unforeseen circumstances (weather, legal, or governmental restrictions) are not the responsibility of Classic SK Home.
  • Any client-requested design or material changes may affect the timeline.

5. Materials and Quality

  • Classic SK Home ensures the use of quality materials as per the specification.
  • Any specific brand or material requested by the client must be communicated in writing.
  • Material shortages or changes in market availability may lead to substitutions of equal quality.

6. Client Responsibilities

  • Clients must provide access to the site and all necessary approvals or legal documents.
  • Water and electricity for construction must be arranged by the client.
  • Any delay due to client-side approval, site issues, or interference will not be the responsibility of Classic SK Home.

7. Warranty and Maintenance

  • Structural work carries a 5-year limited warranty.
  • No warranty on wear and tear, improper use, or damage caused by natural disasters.
  • Plumbing and electrical works carry a 1-year service warranty.

8. Legal Compliance

  • All construction will follow local building codes and government norms.
  • Classic SK Home will assist in obtaining approvals, but final responsibility lies with the client.

9. Termination

  • The agreement can be terminated by either party with 15 days’ written notice.
  • Costs incurred until the date of termination must be paid in full by the client.

10. Dispute Resolution

  • In case of disputes, both parties agree to attempt resolution through negotiation.
  • If unresolved, the matter shall be subject to jurisdiction of the courts in Chennai, Tamil Nadu.